BIDS


NOTICE TO RECEIVE SEALED BIDS
BID #2122-23

The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company, or corporation interested in providing:

WASTE HAULING SERVICES

This includes waste hauling services from their Solid Waste Transfer Station, located at 391 Five Points Rd. in Port St. Joe, FL, to Springhill Landfill, located at 4945 FL-273 in Campbellton, FL. Bids shall be specified at a cost per ton of solid waste rate.

Please place YOUR COMPANY NAME, that this is a SEALED BID, and the BID NUMBER on the outside of your envelope and provide three copies of your proposal.

Bids will be received until 4:00 p.m. Eastern Time, on Friday, May 20, 2022, at the Gulf County Clerk’s Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456, and will be opened at the same location on Monday, May 23, 2022, at 10:00 a.m. Eastern Time.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County. Any questions concerning this bid should be directed to Austin Horton at 850-227-1401 or [email protected].

BOARD OF COUNTY COMMISSIONERS
GULF COUNTY, FLORIDA
/s/ Sandy Quinn, Chairman



NOTICE TO RECEIVE SEALED BIDS
BID #2122-22

The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in selling an:

AERIAL LADDER TRUCK TO SOUTH GULF VOLUNTEER FIRE DEPT

Any bid received must meeting the following standards/specifications for the fire apparatus: 2007 or newer model, less than 50,000 miles, automatic transmission, diesel motor, piped in foam system and 75-foot Aerial Device or taller. All questions must be submitted to Matt Herring at [email protected].

Please place YOUR COMPANY NAME, SEALED BID, and the BID NUMBER on the outside of your envelope and include the original bid, plus 2 copies.

Bids will be received until 4:00 p.m. Eastern Time, on May 20, 2022, at the Gulf County Clerk’s Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456, and will be opened and read aloud at the same location on May 23, 2022, at 10:00 a.m. Eastern Time.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.

BOARD OF COUNTY COMMISSIONERS
GULF COUNTY, FLORIDA
/s/ Sandy Quinn, Chairman



NOTICE TO RECEIVE SEALED BIDS
BID #2122-21

The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:

WHITE CITY PARK PLAYGROUND EQUIPMENT

The project includes the design and installation of playground equipment at the White City Public Boat Ramp Park located at 290 Pridgeon Road in Gulf County, FL.

Completion date for this project will be 60 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be $500.00 per day.

Please place YOUR COMPANY NAME, SEALED BID, and the BID NUMBER on the outside of your envelope and include the original bid, plus 2 copies.

Bids will be received until 4:00 p.m. Eastern Time, on May 20, 2022 at the Gulf County Clerk’s Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456, and will be opened and read aloud at a meeting of the Board of County Commissioners held in the Donald H. Butler Commission Chamber in the Robert M. Moore Administration Building, Gulf County Courthouse Complex, Port St. Joe, Florida on May 24, 2022 at 9:00 a.m. Eastern Time.

Bid specifications can be obtained by CLICKING HERE or through the Gulf County Clerk’s Office. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All questions must be submitted to Clay Smallwood, P.E. at [email protected].

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.

BOARD OF COUNTY COMMISSIONERS
GULF COUNTY, FLORIDA
/s/ Sandy Quinn, Chairman



NOTICE TO RECEIVE SEALED BIDS
BID #2122-18

The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:

CESSNA DRIVE

This project includes approximately 0.92 miles of new roadway construction, installation of approximately 4,600 LF of 6” water main and 4,300 LF of 2” force main along Cessna Drive in Gulf County, FL.

Plans and Specifications can be obtained by contacting Sharon Harrell at [email protected] with Dewberry Engineers Inc, 324 Marina Drive, Port St. Joe, Florida 32456. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Cost for Plans and Specifications will be $25.00 per set and is non-refundable. Checks should be made payable to DEWBERRY ENGINEERS INC.

Completion date for this project will be 180 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $1,694.00 per day.

Please place YOUR COMPANY NAME, SEALED BID, and the BID NUMBER on the outside of your envelope and include the original bid plus 2 copies.

Bids will be received until 4:00 p.m. Eastern Time, on May 20, 2022 at the Gulf County Clerk’s Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456, and will be opened and read aloud at a meeting of the Board of County Commissioners held in the Donald H. Butler Commission Chamber in the Robert M. Moore Administration Building, Gulf County Courthouse Complex, Port St. Joe, Florida on May 24, 2022 at 9:00 a.m. Eastern Time.

All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. All questions must be submitted to Josh Baxley, P.E. at [email protected].

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.

BOARD OF COUNTY COMMISSIONERS
GULF COUNTY, FLORIDA
/s/ Sandy Quinn, Chairman



NOTICE TO RECEIVE SEALED BIDS
BID #2122-13
ADDENDUM 1

The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:

GULF COUNTY WATER SYSTEM IMPROVEMENTS

This project includes construction of a water booster station on Cape San Blas. The station will be installed in line with the existing 8” PVC water main and will consist of a triplex (20 Horsepower each) pump skid designed to automatically boost pressure between the water supply plants called LUCI I and II and the storage and pumping facility known as LUCI III. The skid and electrical components will be housed in a 14 X 20 feet building adjacent to S.R. 30-E (Cape San Blas Road). The project also includes cleaning and painting the hydropnueumatic tank at the LUCI II plant and the following improvements at the LUCI III plant: new generator and automatic transfer switch with electrical upgrades, replacing the ground storage tank roof, finished water flow meter, and general building repairs and painting.

Plans and Specifications can be obtained by contacting Sharon Harrell at [email protected] at Dewberry Engineers Inc, 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to DEWBERRY ENGINEERS INC. If you have any questions, please contact Philip Jones at [email protected].

Completion date for this project will be 300 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day.

Please place YOUR COMPANY NAME, SEALED BID, and the BID NUMBER on the outside of your envelope, and include the original bid, plus 3 copies.

Bids will be received until 4:00 p.m. Eastern Time, on April 22, 2022 at the Gulf County Clerk’s Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456, and will be opened and read aloud at a meeting of the Board of County Commissioners held in the Donald H. Butler Commission Chamber in the Robert M. Moore Administration Building, Gulf County Courthouse Complex, Port St. Joe, Florida on April 26, 2022 at 9:00 a.m. Eastern Time.

All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.


BOARD OF COUNTY COMMISSIONERS
GULF COUNTY, FLORIDA
/s/ Sandy Quinn, Chairman